Education
About Us
Working with TipRanks
Follow Us
NextDecade Corporation (NEXT)
NASDAQ:NEXT
Risk Overview Q3, 2024
Risk Distribution
30% Finance & Corporate
22% Production
20% Legal & Regulatory
13% Ability to Sell
11% Macro & Political
4% Tech & Innovation
Finance & Corporate - Financial and accounting risks. Risks related to the execution of corporate activity and strategy
This chart displays the stock's most recent risk distribution according to category. TipRanks has identified 6 major categories: Finance & corporate, legal & regulatory, macro & political, production, tech & innovation, and ability to sell.
Risk Change Over Time
S&P500 Average
Sector Average
Risks removed
Risks added
Risks changed
NextDecade Risk Factors
New Risk (0)
Risk Changed (0)
Risk Removed (0)
No changes from previous report
The chart shows the number of risks a company has disclosed. You can compare this to the sector average or S&P 500 average.
The quarters shown in the chart are according to the calendar year (January to December). Businesses set their own financial calendar, known as a fiscal year. For example, Walmart ends their financial year at the end of January to accommodate the holiday season.
The quarters shown in the chart are according to the calendar year (January to December). Businesses set their own financial calendar, known as a fiscal year. For example, Walmart ends their financial year at the end of January to accommodate the holiday season.
Risk Highlights Q3, 2024
Main Risk Category
Finance & Corporate
With 14 Risks
Finance & Corporate
With 14 Risks
Number of Disclosed Risks
46
No changes from last report
S&P 500 Average: 31
46
No changes from last report
S&P 500 Average: 31
Recent Changes
1Risks added
0Risks removed
0Risks changed
Since Sep 2024
1Risks added
0Risks removed
0Risks changed
Since Sep 2024
Number of Risk Changed
0
No changes from last report
S&P 500 Average: 3
0
No changes from last report
S&P 500 Average: 3
See the risk highlights of NextDecade in the last period.
Risk Word Cloud
The most common phrases about risk factors from the most recent report. Larger texts indicate more widely used phrases.
Risk Factors Full Breakdown - Total Risks 46
Finance & Corporate
Total Risks: 14/46 (30%)Above Sector Average
Share Price & Shareholder Rights7 | 15.2%
Share Price & Shareholder Rights - Risk 1
Provisions of our charter documents or Delaware law could discourage, delay or prevent us from being acquired even if being acquired would be beneficial to our stockholders and could make it more difficult to change management.Share Price & Shareholder Rights - Risk 2
The exercise of outstanding warrants may have a dilutive effect on our common stock.We issued warrants together with the issuances of our Convertible Preferred Stock (the "Common Stock Warrants"). As of December 31, 2023, the outstanding Common Stock Warrants represented the right to acquire in the aggregate a number of shares of our common stock equal to approximately 71 basis points (0.71%) of all outstanding shares of Company common stock, measured on a fully diluted basis, on the applicable exercise date with a strike price of $0.01 per share.
The Common Stock Warrants have a fixed three-year term that commenced on the closings of the issuances of the associated Convertible Preferred Stock. The Common Stock Warrants may only be exercised by holders of the Common Stock Warrants at the expiration of such three-year term.
To the extent the Common Stock Warrants are exercised, additional shares of our common stock will be issued, which will result in dilution to the holders of our common stock and increase the number of shares eligible for resale in the public market. Sales of substantial numbers of such shares in the public market or the fact that such warrants may be exercised could adversely affect the market price of our common stock.
Share Price & Shareholder Rights - Risk 3
Our largest stockholders will substantially influence our Company for the foreseeable future, including the outcome of matters requiring shareholder approval, and such control may prevent you and other stockholders from influencing significant corporate decisions and may result in conflicts of interest that could cause our stock price to decline.As of March 4, 2024, affiliates of York Capital Management, L.P., TotalEnergies SE, Valinor Capital Partners, L.P., HGC NEXT INV LLC and Ninteenth Investment Company (collectively, the "Large Stockholders") beneficially own, in the aggregate, approximately 60% of the combined voting power of our outstanding shares of common stock. Additionally, four members of our Board of Directors are affiliated with certain of Large Stockholders. As a result, the Large Stockholders have the ability to influence the election of our directors and the outcome of corporate actions requiring stockholder approval, such as: (i) a merger or a sale of our Company, (ii) a sale of all or substantially all of our assets, and (iii) amendments to our articles of incorporation and bylaws. This concentration of voting power and control could have a significant effect in delaying, deferring or preventing an action that might otherwise be beneficial to our other stockholders and be disadvantageous to our stockholders with interests different from those entities and individuals. The Large Stockholders also have significant control over our business, policies and affairs by their affiliates serving as directors of our Company. They may also exert influence in delaying or preventing a change in control of the Company, even if such change in control would benefit the other stockholders of the Company. In addition, the significant concentration of stock ownership may adversely affect the market value of the Company's common stock due to investors' perception that conflicts of interest may exist or arise.
Share Price & Shareholder Rights - Risk 4
Our Second Amended and Restated Certificate of Incorporation grants our board of directors the power to designate and issue additional shares of common and/or preferred stock.Our authorized capital consists of 480,000,000 shares of common stock and 1,000,000 shares of preferred stock. Our preferred stock may be designated into series pursuant to authority granted by our Second Amended and Restated Certificate of Incorporation (the "Certificate of Incorporation"), and on approval from our board of directors (the "Board of Directors" or "Board"). The Board of Directors, without any action by our common stockholders, may designate and issue additional shares of preferred stock in such classes or series as it deems appropriate and establish the rights, preferences and privileges of such shares, including dividends, liquidation and voting rights. The rights of holders of other classes or series of stock that may be issued could be superior to the rights of holders of our common stock. The designation and issuance of shares of capital stock having preferential rights could adversely affect other rights appurtenant to shares of our common stock.
Share Price & Shareholder Rights - Risk 5
Raising additional capital may cause dilution to existing stockholders, restrict our operations or require us to relinquish rights. Additionally, sales of a substantial number of shares of our common stock or other securities in the public market could cause our stock price to fall.We may seek the additional capital necessary to fund our operations through public or private equity offerings and debt financings. To the extent that we raise additional capital through the sale of equity or convertible debt securities, existing stockholders' ownership interests will be diluted, and the terms may include liquidation or other preferences that adversely affect their rights as a stockholder. Debt financing, if available, may involve agreements that include covenants limiting or restricting our ability to take specific actions such as incurring additional debt, making capital expenditures or declaring dividends. In addition, sales of a substantial number of shares of our common stock or other securities in the public market could occur at any time. These sales, or the perception in the market that the holders of a large number of shares intend to sell shares, could reduce the market price of our common stock.
Share Price & Shareholder Rights - Risk 6
The market price of our common stock has fluctuated in the past and is likely to fluctuate in the future. Holders of our common stock could lose all or part of their investment.The securities markets in general and our common stock have experienced significant price and volume volatility. The market price and trading volume of our common stock may continue to experience significant fluctuations due not only to general stock market conditions but also to a change in sentiment in the market regarding our operations, business prospects or those of companies in our industry. In addition to the other risk factors discussed in this section, the price and volume volatility of our common stock may be affected by:
- domestic and worldwide supply of and demand for natural gas and corresponding fluctuations in the price of natural gas;- fluctuations in our quarterly or annual financial results or those of other companies in our industry;- issuance of additional equity securities which causes further dilution to stockholders;- sales of a high volume of shares of our common stock by our stockholders (including sales by our directors, executive officers, and other employees) or the perception or expectation that such sales may occur;- short sales, hedging, and other derivative transactions on shares of our common stock;- the volume of shares of our common stock available for public sale;- operating and stock price performance of companies that investors deem comparable to us;- events affecting other companies that the market deems comparable to us;- changes in government regulation or proposals applicable to us;- actual or potential non-performance by any customer or a counterparty under any agreement;- announcements made by us or our competitors of significant contracts;- changes in accounting standards, policies, guidance, interpretations or principles;- general conditions in the industries in which we operate;- general economic conditions; and - the failure of securities analysts to cover our common stock or changes in financial or other estimates by analysts.
The stock prices of companies in the LNG industry have experienced wide fluctuations that have often been unrelated to the operating performance of these companies. Following periods of volatility in the market price of a company's securities, securities class action litigation often has been initiated against a company. If any class action litigation is initiated against us, we may incur substantial costs and our management's attention may be diverted from our operations, which could materially adversely affect our business and financial condition.
Share Price & Shareholder Rights - Risk 7
Our common stock could be delisted from Nasdaq.Our common stock is currently listed on Nasdaq. However, we cannot assure you that we will be able to comply with the continued listing standards of Nasdaq. If we fail to comply with the continued listing standards of Nasdaq, our common stock may become subject to delisting. If Nasdaq delists our common stock from trading on its exchange for failure to meet the continued listing standards, we and our stockholders could face significant material adverse consequences including:
- a limited availability of market quotations for our securities;- a limited amount of analyst coverage; and - a decreased ability for us to issue additional securities or obtain additional financing in the future.
Accounting & Financial Operations1 | 2.2%
Accounting & Financial Operations - Risk 1
Our ability to utilize our net operating loss carryforwards ("NOLs") may be limited as a result of ownership changes under Section 382 of the Code.Debt & Financing4 | 8.7%
Debt & Financing - Risk 1
Our exposure to the performance and credit risks of counterparties may adversely affect our operating results, liquidity and access to financing.Debt & Financing - Risk 2
We will be required to seek additional debt and equity financing in the future to complete future phases of the Rio Grande LNG Facility and the development of CCS projects and may not be able to secure such financing on acceptable terms, or at all.Since we will be unable to generate any revenue while we are in the development and construction stages, which will be for multiple years with respect to Phase 1 of the Rio Grande LNG Facility, we will need additional financing to provide the capital required to execute our business plan. We will need significant additional funding to develop and construct future phases of the Rio Grande LNG Facility and CCS projects as well as for working capital requirements and other operating and general corporate purposes.
Our ability to obtain the capital necessary to fund development and construction of future projects will depend on the condition of the credit and capital markets, which could become constrained due to factors outside our control. There can be no assurance that we will be able to raise sufficient capital on acceptable terms, or at all. If sufficient capital is not available on satisfactory terms, we may be required to delay, scale back or eliminate the development of business opportunities, and our operations and financial condition may be adversely affected to a significant extent.
Additional debt financing for future phases of development at the Rio Grande LNG Facility, if obtained, may involve agreements that include liens on subsequent trains or other assets and covenants limiting or restricting our ability to take specific actions, such as paying dividends or making distributions, incurring additional debt, acquiring or disposing of assets and increasing expenses. Debt financing would also be required to be repaid regardless of our operating results.
In addition, the ability to obtain financing for future phases of the Rio Grande LNG Facility is expected to be contingent upon, among other things, entry into EPC agreements for construction of subsequent trains and sufficient long-term commercial agreements prior to the commencement of construction. For additional information regarding our ability to enter into such agreements, see "- Our ability to generate cash is substantially dependent upon us entering into satisfactory contracts with third parties and the performance of those third parties under those contracts."
Debt & Financing - Risk 3
Restrictions in debt agreements may prevent certain beneficial transactions.In addition to restrictions on the ability of Rio Grande to make distributions or incur additional indebtedness, the agreements governing Rio Grande's indebtedness also contain various other covenants that may prevent it from engaging in beneficial transactions, including limitations on the ability of Rio Grande or certain of its subsidiaries to:
- make distributions or certain investments;- incur additional indebtedness;- purchase, redeem or retire equity interests;- sell or transfer assets;- incur liens;- enter into transactions with affiliates; and - consolidate, merge, sell or lease all or substantially all of its assets.
A breach of the covenants and other restrictions in any of Rio Grande's indebtedness could result in an event of default thereunder. Such a default may allow the holders of such indebtedness to accelerate the related indebtedness which may result in foreclosure on Rio Grande's assets.
Additionally, NextDecade LLC has entered into a credit agreement (the "NextDecade Credit Agreement") that provides for a $50 million revolving loan facility. The NextDecade Credit Agreement includes covenants that, among other things, limit the ability of NextDecade LLC to incur additional indebtedness, make certain investments or pay dividends or distributions on equity interests or subordinated indebtedness or purchase, redeem, or retire equity interests, sell or transfer assets, incur liens or dissolve, liquidate, consolidate, merge. Upon the occurrence and continuation of an event of default under the NextDecade Credit Agreement (and after all applicable cure periods have elapsed), the required lenders may, by notice to NextDecade LLC accelerate the loans thereunder, suspend or terminate all outstanding loan commitments under the NextDecade Credit Agreement and exercise remedies in respect of the collateral.
Debt & Financing - Risk 4
The substantial amount of indebtedness incurred to finance construction of Phase 1 of the Rio Grande LNG Facility may adversely affect Rio Grande's cash flow and its ability to operate its business, remain in compliance with debt covenants and make payments on its indebtedness.Rio Grande has incurred a substantial amount of indebtedness. This substantial level of indebtedness increases the possibility that Rio Grande may be unable to generate cash sufficient to pay, when due, the principal or interest on such indebtedness or to refinance such indebtedness ahead of its scheduled maturity. This indebtedness and obligations thereunder could have other important consequences to you as a stockholder. For example:
- any failure to comply with the obligations of any of Rio Grande's debt instruments, including financial and other restrictive covenants, could result in an event of default under the applicable instrument;- Rio Grande may be more vulnerable to adverse changes in general economic, industry and competitive conditions and adverse change in government regulation affecting Rio Grande's ability to pay obligations when due;- Rio Grande may need to dedicate a substantial portion of its future cashflow from operations to payments on indebtedness, thereby reducing the availability of cash flows to fund working capital, capital expenditures, acquisitions, other general corporate purposes and any future dividends or share repurchases;- the ability to refinance Rio Grande's indebtedness will depend on the condition of credit markets and capital markets, and its financial condition at such time. Any refinancing could be at higher interest rates and may require compliance with more onerous covenants, which could further restrict business operations;- we may have limited flexibility in planning for, or reacting to, changes in Rio Grande's business and the industry in which it operates; and - our indebtedness may place Rio Grande at a competitive disadvantage compared to its competitors that have less debt.
Corporate Activity and Growth2 | 4.3%
Corporate Activity and Growth - Risk 1
Conducting a portion of our operations through joint ventures in which we do not have 100% ownership interest, and which are not operated solely for the benefit of our stockholders, exposes us and our stockholders to risks and uncertainties, many of which are outside of our control.Corporate Activity and Growth - Risk 2
There is substantial doubt about our ability to continue as a going concern.We have incurred operating losses since our inception and management expects operating losses and negative cash flows to continue for the foreseeable future and, as a result, we will require additional capital to fund our operations and execute our business plan. As of December 31, 2023, the Company had $38.2 million in cash and cash equivalents, which may not be sufficient to fund the Company's planned operations through one year after the date the consolidated financial statements are issued. Accordingly, there is substantial doubt about the Company's ability to continue as a going concern. The analysis used to determine the Company's ability to continue as a going concern does not include cash sources outside of the Company's direct control that management expects to be available within the next twelve months.
Our ability to continue as a going concern is dependent upon our ability to obtain sufficient funding through additional debt or equity financing and to manage operating and overhead costs. There can be no assurance that we will be able to raise sufficient capital on acceptable or favorable terms to the Company, or at all.
Production
Total Risks: 10/46 (22%)Above Sector Average
Manufacturing5 | 10.9%
Manufacturing - Risk 1
The operation of the Rio Grande LNG Facility and any CCS project may be subject to significant operating hazards and uninsured risks, one or more of which may create significant liabilities and losses that could have a material adverse effect on our business, results of operations, financial condition, liquidity and prospects.Manufacturing - Risk 2
There may be shortages of LNG vessels worldwide, which could have a material adverse effect on our business, results of operations, financial condition, liquidity and prospects.The construction and delivery of LNG vessels requires significant capital and long construction lead times, and the availability of the vessels could be delayed to the detriment of our business and customers due to the following:
- an inadequate number of shipyards constructing LNG vessels and a backlog of orders at these shipyards;- political or economic disturbances in the countries where the vessels are being constructed;- changes in governmental regulations or maritime self-regulatory organizations;- work stoppages or other labor disturbances at the shipyards;- bankruptcies or other financial crises of shipbuilders;- quality or engineering problems;- weather interference or catastrophic events, such as a major earthquake, tsunami, or fire; or - shortages of or delays in the receipt of necessary construction materials.
Manufacturing - Risk 3
Our construction and operations activities will be subject to a number of development risks, operational hazards, regulatory approvals and other risks which may not be fully covered by insurance, and which could cause cost overruns and delays that could have a material adverse effect on our business, results of operations, financial condition, liquidity and prospects.Development and construction of the Rio Grande LNG Facility and CCS projects will be subject to the risks of delay or cost overruns inherent in any construction project resulting from numerous factors, including, but not limited to, the following:
- difficulties or delays in obtaining, or failure to obtain, sufficient debt or equity financing on reasonable terms;- failure to obtain or maintain all necessary government and third-party permits, approvals and licenses, or to comply with all the terms and conditions of those authorizations, for the construction and operation of the Rio Grande LNG Facility and CCS projects;- failure to obtain or maintain commercial agreements that generate sufficient revenue to support the financing and construction of the Rio Grande LNG Facility or CCS projects;- difficulties in engaging qualified contractors necessary to the construction of the contemplated Rio Grande LNG Facility or CCS projects;- shortages of equipment, materials or skilled labor;- natural disasters and catastrophes, such as hurricanes, explosions, fires, floods, industrial accidents and terrorism;- delays in the delivery of ordered materials;- work stoppages and labor disputes;- opposition from environmental and social groups, landowners, tribal groups, local groups and other advocates could result in organized protests, attempts to block or sabotage our construction activities or operations, intervention in regulatory or administrative proceedings involving our assets, or lawsuits or other actions designed to prevent, disrupt or delay the construction or operation of the Rio Grande LNG Facility or CCS projects;- competition with other domestic and international LNG export facilities;- unanticipated changes in domestic and international market demand for and supply of natural gas and LNG, which will depend in part on supplies of and prices for alternative energy sources and the discovery of new sources of natural resources;- insufficiency in domestic and international market demand for verified carbon capture credits;- unexpected or unanticipated additional improvements; and - adverse general economic conditions.
Delays beyond the estimated development periods, as well as cost overruns, could increase the cost of completion beyond the amounts that are currently estimated, which could require us to obtain additional sources of financing to fund the activities until the Rio Grande LNG Facility is constructed and operational, which could cause further delays. The need for additional financing may also make the Rio Grande LNG Facility uneconomic. Any delay in completion of the Rio Grande LNG Facility may also cause a delay in the receipt of revenues projected from the Rio Grande LNG Facility or cause a loss of one or more customers. As a result, any significant construction delay, whatever the cause, could have a material adverse effect on our business, results of operations, financial condition, liquidity and prospects.
Rio Grande LNG Facility operations will be subject to all of the hazards inherent in the receipt and processing of natural gas to LNG, and associated short-term storage including:
- damage to pipelines and plants, related equipment, loading terminal, and surrounding properties caused by hurricanes, tornadoes, floods, fires and other natural disasters, acts of terrorism and acts of third parties;- damage from subsurface and/or waterway activity (for example, sedimentation of shipping channel access);- leaks of natural gas, or natural gas liquids, or losses of natural gas, or natural gas liquids, as a result of the malfunction of equipment or facilities;- fires, ruptures and explosions;- other hazards that could also result in personal injury and loss of life, pollution and suspension of operations; and - hazards experienced by other operators that may affect our operations by instigating increased regulations and oversight.
Any of these risks could adversely affect our ability to conduct operations or result in substantial loss to us as a result of claims for:
- injury or loss of life;- damage to and destruction of property, natural resources and equipment;- pollution and other environmental damage;- regulatory investigations and penalties;- suspension of our operations;- failure to perform contractual obligations; and - repair and remediation costs.
Due to the scale of the Rio Grande LNG Facility, we may encounter capacity limits in insurance markets, thereby limiting our ability to economically obtain insurance with our desired level of coverage limits and terms. With respect to the Rio Grande LNG Facility or CCS projects, we may elect not to obtain insurance for any or all of these risks if we believe that the cost of available insurance is excessive relative to the risks presented. In addition, contractual liabilities and pollution and environmental risks generally are not fully insurable. The occurrence of an event that is not fully covered by insurance could have a material adverse effect on our business, financial condition and results of operations.
Manufacturing - Risk 4
The Rio Grande LNG Facility's operations will be substantially dependent on the development and operation of the Pipeline by Enbridge and its affiliates.The Rio Grande LNG Facility will be dependent on a pipeline owned by an affiliate of Enbridge (the "Transporter") for the delivery of all of its natural gas. The Pipeline is currently in development and its construction will require the Transporter to secure rights-of-way along the proposed Pipeline route. It is possible that, in negotiating to secure these rights-of-way, the Transporter encounters recalcitrant landowners or competitive projects, which could result in additional time needed to secure the Pipeline route and, consequently, delays in, or abandonment of, its construction. Construction of the Pipeline could be delayed or abandoned for any of many other reasons, such as it becoming economically disadvantageous to the Transporter, a failure to obtain or maintain all necessary permits, approvals and licenses for the construction and operation, mechanical or structural failures, inadvertent damages during construction, natural disasters, or any terrorist attack, including cyberterrorism, affecting the Pipeline or the Transporter. Any such delays in the construction of the Pipeline could delay the development of the Rio Grande LNG Facility and its becoming operational.
Manufacturing - Risk 5
Our projects are in the development and construction phases, and the success of such projects is unpredictable; as such, positive cash flows and even revenues will be several years away, if they occur at all.We are not expected to generate cash flow, or even obtain revenues, from our LNG liquefaction and export activities unless and until the Rio Grande LNG Facility is operational. Additionally, we do not expect to generate cash flow from our CCS projects until we install CCS systems at the Rio Grande LNG Facility or on third-party industrial facilities. Accordingly, distributions to investors may be limited, delayed, or non-existent.
Our cash flow and consequently our ability to distribute earnings will be dependent upon our ability to complete Phase 1 of the Rio Grande LNG Facility and future phases of development and implement CCS systems and thereafter generate cash and net operating income from operations. Rio Grande's ability to complete the Rio Grande LNG Facility, as discussed further below, is dependent upon, among other things, performance of third-party contractors and customers under their agreements with Rio Grande. NEXT Carbon Solutions' ability to install CCS systems at third-party industrial facilities, as discussed further below, is dependent on the development of front-end engineering and design ("FEED") offerings and contracting with third parties to install CCS systems in their industrial facilities. We do not expect Rio Grande to generate any revenue until the completion of construction of Phase 1 of the Rio Grande LNG Facility or NEXT Carbon Solutions to generate any revenue until successful installation of CCS systems at third-party facilities. After Phase 1 of the Rio Grande LNG Facility is completed or our CCS systems are installed in third-party industrial facilities, financing and numerous other factors may reduce our cash flow. As a result, we may not make distributions of any amount or any distributions may be delayed.
Employment / Personnel1 | 2.2%
Employment / Personnel - Risk 1
We may experience increased labor costs, and the unavailability of skilled workers or our failure to attract and retain qualified personnel could adversely affect us. In addition, changes in our senior management or other key personnel could affect our business operations.Supply Chain3 | 6.5%
Supply Chain - Risk 1
We will rely on third-party engineers to estimate the future capacity ratings and performance capabilities of the Rio Grande LNG Facility and CCS projects, and these estimates may prove to be inaccurate.Supply Chain - Risk 2
The Rio Grande LNG Facility will be dependent on the availability of gas supply at the Agua Dulce supply area.The Pipeline is expected to collect and transport natural gas to the Rio Grande LNG Facility. The header system at the upstream end of the Pipeline is expected to have multiple interconnects to the existing natural gas pipeline grid located in the Agua Dulce supply area (the "Agua Dulce Hub"). The Agua Dulce Hub includes deliveries from, but not limited to, ConocoPhillips' 1,100-mile South Texas intrastate and gas gathering pipeline system and ExxonMobil's 925 MMcf/d King Ranch processing facility. As the Pipeline system interconnects are expected to be relatively close to the Agua Dulce Hub, it is expected that gas will be available for purchase in large volumes at commercially acceptable prices. Nonetheless, disruptions in upstream supply sources or increased market demand could impact the availability of gas supply to the Pipeline header system, which would result in curtailments at the Rio Grande LNG Facility.
Each liquefaction train for the Rio Grande LNG Facility is expected to involve the transportation on the Pipeline for liquefaction of approximately 0.9 Bcf/day of natural gas, for a total of 4.5 Bcf/day for five liquefaction trains at full build-out. Gas sales agreements for the supply of these volumes could entail negotiations with multiple parties for firm and interruptible gas supply and transportation services to the Pipeline header system, as well as pipeline interconnects and ancillary operational agreements. Delays caused by third parties in the course of negotiating agreements and constructing the required interconnects could delay the start of commercial operations for the Rio Grande LNG Facility.
Supply Chain - Risk 3
We will be dependent on third-party contractors for the successful completion of the Rio Grande LNG Facility and CCS projects, and these contractors may be unable to complete the Rio Grande LNG Facility or CCS projects or may build a non-conforming Rio Grande LNG Facility or CCS projects.The construction of the Rio Grande LNG Facility is expected to take several years, will be confined to a limited geographic area and could be subject to delays, cost overruns, labor disputes and other factors that could adversely affect financial performance or impair our ability to execute our scheduled business plan.
Timely and cost-effective completion of the Rio Grande LNG Facility and any CCS projects in conformity with agreed-upon specifications will be highly dependent upon the performance of third-party contractors pursuant to their agreements. We have not yet entered into definitive agreements with certain of the contractors, advisors and consultants necessary for the development and construction for future phases of development at the Rio Grande LNG Facility or any CCS projects. We may not be able to successfully enter into such construction agreements on terms or at prices that are acceptable to us.
Further, faulty construction that does not conform to our design and quality standards may have an adverse effect on our business, results of operations, financial condition and prospects. For example, improper equipment installation may lead to a shortened life of our equipment, increased operations and maintenance costs or a reduced availability or production capacity of the affected facility. The ability of our third-party contractors to perform successfully under any agreements to be entered into is dependent on a number of factors, including force majeure events and such contractors' ability to:
- design, engineer and receive critical components and equipment necessary for the Rio Grande LNG Facility and CCS projects to operate in accordance with specifications and address any start-up and operational issues that may arise in connection with the commencement of commercial operations;- attract, develop and retain skilled personnel and engage and retain third-party subcontractors, and address any labor issues that may arise;- post required construction bonds and comply with the terms thereof, and maintain their own financial condition, including adequate working capital;- adhere to any warranties the contractors provide in their EPC contracts; and - respond to difficulties such as equipment failure, delivery delays, schedule changes and failure to perform by subcontractors, some of which are beyond their control, and manage the construction process generally, including engaging and retaining third-party contractors, coordinating with other contractors and regulatory agencies and dealing with inclement weather conditions.
Furthermore, we may have disagreements with our third-party contractors about different elements of the construction process, which could lead to the assertion of rights and remedies under the related contracts, resulting in a contractor's unwillingness to perform further work on the relevant project. We may also face difficulties in commissioning a newly constructed facility at the Rio Grande LNG Facility. Any of the foregoing issues or significant project delays in the development or construction of the Rio Grande LNG Facility and, to the extent applicable, CCS projects could materially and adversely affect our business, results of operations, financial condition and prospects.
Costs1 | 2.2%
Costs - Risk 1
Costs for the Rio Grande LNG Facility and CCS projects are subject to various factors.Legal & Regulatory
Total Risks: 9/46 (20%)Above Sector Average
Regulation3 | 6.5%
Regulation - Risk 1
The construction and operation of the Rio Grande LNG Facility remains subject to further governmental approvals, and some approvals may be subject to further conditions, review and/or revocation and other legal and regulatory risks, which may result in delays, increased costs or decreased cash flows.Regulation - Risk 2
Changes in legislation and regulations or interpretations thereof, such as those relating to the importation and exportation of LNG and incentives for reduction of emissions, could have a material adverse effect on our business, results of operations, financial condition, liquidity and prospects and could cause additional expenditures and delays in connection with the Rio Grande LNG Facility and CCS projects and their construction.The laws, rules and regulations applicable to our business, including federal agencies' interpretations of and policies under such laws rules and regulations, are subject to change, either through new or modified regulations enacted on the federal, state or local level or by a change in policy of the agencies charged with enforcing such regulations. For example, the provisions of the Energy Policy Act of 2005 that codified the FERC's policy of not regulating the terms and conditions of service for LNG import or export facilities expired in 2015. Although the FERC has not indicated that it intends to depart from this policy, there can be no assurance it will not do so in the future. The nature and extent of any changes in these laws, rules, regulations and policies may be unpredictable and may have material adverse effects on our business. Future legislation and regulations or changes in existing legislation and regulations, or interpretations thereof, such as those relating to (i) the liquefaction, storage, or regasification of LNG, or its transportation, and (ii) the capture of CO2, its transportation and sequestration, could cause additional expenditures, restrictions and delays in connection with our operations as well as other future projects, the extent of which cannot be predicted and which may require us to limit substantially, delay or cease operations in some circumstances. Revised, reinterpreted or additional laws and regulations that result in increased compliance costs or additional operating costs and restrictions could have a material adverse effect on our business, the ability to expand our business, including into new markets, results of operations, financial condition, liquidity and prospects.
In addition, our CCS systems may benefit from federal, state and local governmental incentives, mandates or other programs promoting the reduction of emissions. Any changes to or termination of these programs could reduce demand for our CCS systems, impair our ability to obtain financing, and adversely impact our business, financial condition and results of operations.
Regulation - Risk 3
Unethical conduct and non-compliance with applicable laws could have a significant adverse effect on our business.Incidents of unethical behavior, fraudulent activity, corruption or non-compliance with applicable laws and regulations could be damaging to our operations and reputation and may subject us to criminal and civil penalties or loss of operating licenses. Due to the global nature of the LNG business and the diversity of jurisdictions in which our customers operate, it is possible that a prospective counterparty could be accused of behavior that falls short of our expectations in this regard, leading to reputational damage and potential legal liabilities, notwithstanding our best efforts to prevent such behaviors.
Litigation & Legal Liabilities2 | 4.3%
Litigation & Legal Liabilities - Risk 1
Litigation could expose us to significant costs and adversely affect our business, financial condition, and results of operations.Litigation & Legal Liabilities - Risk 2
The decision by the D.C. Circuit Court of Appeals could impact Rio Grande's ability to complete Phase 1 on the expected time frame or at all, our ability to take a final investment decision on expansion trains at the Rio Grande LNG Facility and our ability to achieve expected investment returns.Added
We are required to obtain and maintain governmental approvals and authorizations to implement our proposed business strategy, which includes the design, construction and operation of the Rio Grande LNG Facility and the export of LNG from the U.S. to foreign countries. As described in more detail in "Item 2. Management's Discussion and Analysis of Financial Condition and Results of Operations-Overview of Business and Significant Developments-Significant Recent Developments-Regulatory," on August 6, 2024, the D.C. Circuit Court of Appeals vacated the FERC reauthorization for the siting, construction and operation of the Rio Grande LNG Facility. We intend to pursue available legal remedies against judicial challenges and are engaged in active resolution of the requisite issues to ensure that the affected permit remains in effect; however, there is no guarantee as to how long any agency proceedings and judicial challenges will take to resolve, whether there will be any delays in construction activities or whether Rio Grande will ultimately succeed in maintaining the permit in its issued form or in a suitable replacement form. These uncertainties could cause Rio Grande to be subject to increased costs and adverse impact to its ability to complete the construction of Phase 1 on a timely basis or at all, which in turn could adversely affect the ability for Rio Grande and its owners, including us, to successfully implement our business strategy or achieve expected returns. Similarly, these uncertainties could impact the timing of, and our ability to take, a final investment decision on any expansion trains at the Rio Grande LNG Facility. In addition, the bank credit facilities obtained by Rio Grande to finance a substantial portion of Phase 1 costs require maintenance of material governmental approvals. To the extent Rio Grande becomes unable to satisfy such requirement as set forth in the credit agreements or reach other accommodations with its lenders, its ability to continue borrowing under such credit facilities could be negatively impacted, which in turn could adversely affect our business, financial condition, results of operations and liquidity.
Taxation & Government Incentives2 | 4.3%
Taxation & Government Incentives - Risk 1
We may not be able to utilize any future federal income tax credits.Taxation & Government Incentives - Risk 2
The reduction or elimination of government incentives could adversely affect our business, financial condition, future results and cash flows.We expect our CCS projects, following successful construction and deployment, to generate revenue from a combination of sources, including fees from source facilities, government incentives and carbon credits. Government incentives include federal income tax credits under Section 45Q of the Internal Revenue Code, which currently provides a federal income tax credit per metric ton of carbon captured and permanently stored. The availability of these government incentives have a significant effect on the economics and viability of our CCS projects, and any reduction or elimination of such incentives could adversely affect the growth of our CCS business, our financial condition and our future results.
Environmental / Social2 | 4.3%
Environmental / Social - Risk 1
The Rio Grande LNG Facility will be subject to a number of environmental laws and regulations that impose significant compliance costs, and existing and future environmental and similar laws and regulations could result in increased compliance costs, liabilities or additional operating restrictions.Environmental / Social - Risk 2
Increasing attention to environmental, social and governance matters may impact our business, financial results or stock price and climate change concerns may pose challenges to our operating model.In recent years, increasing attention has been given to corporate activities related to environmental, social and governance matters in public discourse and the investment community. A number of advocacy groups, both domestically and internationally, have campaigned for governmental and private action to promote change at public companies related to ESG matters, including through the investment and voting practices of investment advisers, public pension funds, universities and other members of the investing community. These activities include increasing attention and demands for action related to climate change, promoting the use of substitutes to fossil fuel products, and encouraging the divestment of companies in the fossil fuel industry. These activities could negatively impact negotiations with potential customers or financial counterparties, reduce demand for our products, reduce our profits, increase the potential for investigations and litigation, impair our brand and have negative impacts on the price of our common stock and access to capital markets.
In October 2020, we announced that we have developed proprietary CCS processes, which we intend to deploy at the Rio Grande LNG Facility to significantly reduce its expected CO2 emissions. However, the Rio Grande LNG Facility CCS project may ultimately be unsuccessful or, even if successful, may not satisfy the demands or expectations of certain members of the investing community focused on ESG matters.
In addition, organizations that provide information to investors on corporate governance and related matters have developed ratings systems for evaluating companies on their approach to ESG matters. Recently, there has been an acceleration in investor demand for ESG investing opportunities, and many large institutional investors have committed to increasing the percentage of their portfolios that are allocated towards ESG-focused investments. As a result, there has been a proliferation of ESG-focused investment funds seeking ESG-oriented investment products. If we are unable to meet the ESG ratings or investment or lending criteria set by these investors and funds, we may lose investors, investors may allocate a portion of their capital away from us, our cost of capital may increase, the price of our common stock may be negatively impacted, and our reputation may also be negatively affected.
Furthermore, we also could face an increased risk of climate-related litigation suits with respect to our operations or disclosures. Claims have been made against certain energy companies alleging that greenhouse gas emissions from oil, gas and LNG operations constitute a public nuisance under federal and state law. Private individuals or public entities also could attempt to enforce environmental laws and regulations against us and could seek personal injury and property damages or other remedies. Additionally, governments and private parties are also increasingly filing suits, or initiating regulatory action, based on allegations that certain public statements regarding ESG-related matters by companies are false and misleading "greenwashing" campaigns that violate deceptive trade practices and consumer protection statutes or that climate-related disclosures made by companies are inadequate. Similar issues can also arise when aspirational statements such as net-zero or carbon neutrality targets are made without clear plans. Although we are not a party to any such climate-related or "greenwashing" litigation currently, unfavorable rulings against us in any such case brought against us in the future could significantly impact our operations and could have an adverse impact on our financial condition.
Ability to Sell
Total Risks: 6/46 (13%)Above Sector Average
Competition3 | 6.5%
Competition - Risk 1
Failure of exported LNG to be a competitive source of energy for international markets could adversely affect our customers and could materially and adversely affect our business, contracts, financial condition, operating results, cash flow, liquidity and prospects.Competition - Risk 2
Technological innovation, competition or other factors may negatively impact our anticipated competitive advantage or our processes.Our success will depend on our ability to create and maintain a competitive position in the natural gas liquefaction and carbon capture and storage industries. We do not have any exclusive rights to any of the liquefaction technologies that we will be utilizing in the Rio Grande LNG Facility. In addition, the LNG technology we are using in the Rio Grande LNG Facility may face competition due to the technological advances of other companies or solutions, including more efficient and cost-effective processes or entirely different approaches developed by one or more of our competitors or others. Although we have applied for and obtained patents relating to our CCS processes and rely on other procedures to protect our intellectual property, we may be unable to prevent third parties from utilizing our intellectual property; see "- We depend on our intellectual property for our CCS projects, and our failure to protect that intellectual property could adversely affect the future growth and success of our CCS business."
Continuing technological changes in the market for carbon capture solutions could make our CCS projects less competitive or obsolete, either generally or for particular applications. Our future success will depend upon our ability to develop and introduce a variety of new capabilities and enhancements to our CCS offerings to address the changing needs of the carbon capture markets. Delays in introducing enhancements, the failure to choose correctly among technical alternatives or the failure to offer innovative products or enhancements at competitive prices may cause existing and potential customers to utilize competing projects or solutions.
Competition - Risk 3
Competition in the industries in which we operate is intense, and some of our competitors have greater financial, technological and other resources.We plan to operate in the highly competitive area of LNG production and face intense competition from independent, technology-driven companies as well as from both major and other independent oil and natural gas companies and utilities.
Many competing companies have secured access to, or are pursuing development or acquisition of, LNG facilities and deployment of carbon capture processes in North America. We may face competition from major energy companies and others in pursuing our proposed business strategy. Some of these competitors have longer operating histories, more development experience, greater name recognition, superior tax incentives, more employees and substantially greater financial, technical and marketing resources than we currently possess. NEXT Carbon Solutions will compete with other providers of CCS services, traditional original equipment manufacturers, EPC firms and midstream transportation and storage companies in offering CCS solutions. Our competitors in the CCS space may have greater financial, technical and marketing resources than we currently possess. The superior resources that some of these competitors have available for deployment could allow them to compete successfully against us, which could have a material adverse effect on our business, results of operations, financial condition, liquidity and prospects.
Demand2 | 4.3%
Demand - Risk 1
We are dependent on a limited number of customers for the purchase of LNG.Demand - Risk 2
Decreases in the global demand for and price of natural gas (versus the price of imported LNG) could lead to reduced development of LNG projects worldwide.We are subject to risks associated with the development, operation and financing of domestic LNG facilities. The development of domestic LNG facilities and projects is generally based on assumptions about the future price of natural gas and LNG and the conditions of the global natural gas and LNG markets. Natural gas and LNG prices have been, and are likely to remain in the future, volatile and subject to wide fluctuations that are difficult to predict. As a result, our activities will expose us to risks of commodity price movements, which we believe could be mitigated by entering into long-term LNG sales contracts. There can be no assurance that we will be successful in entering into or maintaining long-term LNG sales contracts. Additionally, the global LNG market could shift toward the use of shorter-term LNG sales contracts.
Fluctuations in commodity prices may create a mismatch between natural gas and petroleum prices, which could have a significant impact on our future revenues. Commodity prices and volumes are volatile due to many factors over which we have no control, including competing liquefaction capacity in North America; the international supply and receiving capacity of LNG; LNG marine transportation capacity; weather conditions affecting production or transportation of LNG from the Rio Grande LNG Facility; domestic and global demand for natural gas; the effect of government regulation on the production, transportation and sale of natural gas; oil and natural gas exploration and production activities; the development of and changes in the cost of alternative energy sources for natural gas and political and economic conditions worldwide.
Our activities are also dependent on the price and availability of materials for the construction of the Rio Grande LNG Facility, such as nickel, aluminum, pipe, and steel, which may be subject to import tariffs in the U.S. market and are all also subject to factors affecting commodity prices and volumes. In addition, authorities with jurisdiction over wholesale power rates in the U.S., Europe and elsewhere, as well as independent system operators overseeing some of these markets, may impose price limitations, bidding rules and other mechanisms which may adversely impact or otherwise limit trading margins and lead to diminished opportunities for gain. We cannot predict the impact energy trading may have on our business, results of operations or financial condition.
Further, the development of the Rio Grande LNG Facility takes a substantial amount of time, requires significant capital investment, may be delayed by unforeseen and uncontrollable factors and is dependent on our financial viability and ability to market LNG internationally.
Sales & Marketing1 | 2.2%
Sales & Marketing - Risk 1
Our ability to generate cash is substantially dependent upon us entering into satisfactory contracts with third parties and the performance of those third parties under those contracts.Macro & Political
Total Risks: 5/46 (11%)Above Sector Average
International Operations1 | 2.2%
International Operations - Risk 1
We may be subject to risks related to doing business in, and having counterparties based in, foreign countries.Natural and Human Disruptions3 | 6.5%
Natural and Human Disruptions - Risk 1
Objections from local communities or environmental groups can delay the Rio Grande LNG Facility.Natural and Human Disruptions - Risk 2
Terrorist attacks, including cyberterrorism, or military campaigns involving us or our projects could result in delays in, or cancellation of, construction or closure of the Rio Grande LNG Facility.A terrorist or military incident involving the Rio Grande LNG Facility or any industrial facility that hosts a CCS project may result in delays in, or cancellation of, construction of the Rio Grande LNG Facility or the relevant CCS project, which would increase our costs and prevent us from obtaining expected cash flows. A terrorist incident could also result in temporary or permanent closure of the Rio Grande LNG Facility or such host industrial facility, which could increase costs and decrease cash flows, depending on the duration of the closure. Operations at the Rio Grande LNG Facility and CCS projects could also become subject to increased governmental scrutiny that may result in additional security measures at a significant incremental cost. In addition, the threat of terrorism and the impact of military campaigns may lead to continued volatility in prices for natural gas that could adversely affect our business and customers, including the ability of our suppliers or customers to satisfy their respective obligations under our commercial agreements. Instability in the financial markets as a result of terrorism, including cyberterrorism, or war, including the Russia-Ukraine conflict or hostilities in the Middle East, could also materially adversely affect our ability to raise capital. The continuation of these developments may subject our construction and operations to increased risks, as well as increased costs, and, depending on their ultimate magnitude, could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, liquidity and prospects.
Natural and Human Disruptions - Risk 3
The COVID-19 pandemic, Russia-Ukraine conflict, conflict in the Middle East and other sources of volatility in the energy markets may materially and adversely affect our business, financial condition, operating results, cash flow, liquidity and prospects, including our efforts to reach a final investment decision with respect to the Rio Grande LNG Facility.The COVID-19 pandemic has resulted in significant disruption globally. Actions taken by various governmental authorities, individuals and companies around the world to prevent the spread of COVID-19 have restricted travel, business operations, and the overall level of individual movement and in-person interaction across the globe. Furthermore, the impact of the pandemic, including its effect on the demand for natural gas, led to significant global economic contraction generally and in our industry in particular. Prospects for the development and financing of the Rio Grande LNG Facility are based in part on factors including global economic conditions that have been, and are likely to continue to be, adversely affected by the COVID-19 pandemic.
The COVID-19 pandemic has caused us to modify our business practices, including by restricting employee travel, requiring employees to work remotely and cancelling physical participation in meetings, events and conferences, and we may take further actions as may be required by government authorities or that we determine are in the best interests of our employees, customers and business partners. There is no certainty that such measures will be sufficient to mitigate the risks posed by COVID-19 or otherwise be satisfactory to government authorities. If a number of our employees were to contract COVID-19 at the same time, our operations could be adversely affected.
In February 2022, Russia, one of the world's largest producers of natural gas, launched an invasion of Ukraine. These actions resulted in a number of countries, including the United States and members of the European Union, announcing sanctions against Russia. Additionally, the Nord Stream 2 gas pipeline project, which was built to provide 55 billion cubic meters of natural gas to Europe annually, has been affected by geopolitical issues and incurred damage that has been investigated as possible sabotage. The current geopolitical climate in Europe is unstable and conflict may further escalate. While it is difficult to anticipate the impact the sanctions announced to date may have on our operations, any further sanctions imposed or actions taken by the U.S. or other countries, and any retaliatory measures by Russia in response, such as restrictions on energy supplies from Russia to countries in the region, could have a significant and uncertain impact on the natural gas industry. In addition, the Israel-Hamas war and maritime attacks in the Red Sea have caused further geopolitical uncertainty, especially as it related to the energy industry.
A sustained disruption in the capital markets from the COVID-19 pandemic or the Russia-Ukraine conflict and hostilities in the Middle East, specifically with respect to the energy industry, could negatively impact our ability to raise capital. In the past, we have financed our operations by the issuance of equity and equity-based securities. However, we cannot predict when macro-economic disruption stemming from COVID-19 or outbreaks of variants of the virus or geopolitical uncertainty may occur. This macro-economic disruption may disrupt our ability to raise additional capital to finance our operations in the future, which could materially and adversely affect our business, financial condition and prospects, and could ultimately cause our business to fail.
The COVID-19 pandemic and Russia-Ukraine conflict may also have the effect of heightening many of the other risks described in this Annual Report on Form 10-K, such as risks related to the development of the CCS projects and the Rio Grande LNG Facility, including postponement in making a positive FID on the Rio Grande LNG Facility, doing business in foreign countries, obtaining governmental approvals, and exported LNG remaining a competitive source of energy for international markets, global demand for and price of natural gas, and fluctuation in the price of our common stock.
The extent to which COVID-19 ultimately impacts our business, results of operations and financial condition depends on future developments, which are uncertain and cannot be predicted, including, but not limited to, the duration and spread of COVID-19, its severity, the actions to contain COVID-19 or treat its impact, and how quickly and to what extent normal economic and operating conditions can resume. Additionally, the ultimate outcome of Russia's invasion of Ukraine, including resulting tensions among the United States, North Atlantic Treaty Organization and Russia, disruption to the production and supply of natural gas throughout Europe, cyberwarfare and economic instability, could impact our operations or disrupt our ability to access the capital markets. The duration of the impact of the COVID-19 pandemic, the Russia-Ukraine conflict and hostilities in the Middle East is uncertain, and we may continue to experience materially adverse impacts to our business as a result of their global economic impact, including any recession that has occurred or may occur in the future, and lasting effects on the price of natural gas.
Capital Markets1 | 2.2%
Capital Markets - Risk 1
Carbon credit markets may not develop as quickly or efficiently as we anticipate or at all.Tech & Innovation
Total Risks: 2/46 (4%)Above Sector Average
Trade Secrets1 | 2.2%
Trade Secrets - Risk 1
We depend on our intellectual property for our CCS projects, and our failure to protect that intellectual property could adversely affect the future growth and success of our CCS business.Cyber Security1 | 2.2%
Cyber Security - Risk 1
Cyberattacks targeting systems and infrastructure used in our business may adversely impact our operations.See a full breakdown of risk according to category and subcategory. The list starts with the category with the most risk. Click on subcategories to read relevant extracts from the most recent report.
FAQ
What are “Risk Factors”?
Risk factors are any situations or occurrences that could make investing in a company risky.
The Securities and Exchange Commission (SEC) requires that publicly traded companies disclose their most significant risk factors. This is so that potential investors can consider any risks before they make an investment.
They also offer companies protection, as a company can use risk factors as liability protection. This could happen if a company underperforms and investors take legal action as a result.
It is worth noting that smaller companies, that is those with a public float of under $75 million on the last business day, do not have to include risk factors in their 10-K and 10-Q forms, although some may choose to do so.
How do companies disclose their risk factors?
Publicly traded companies initially disclose their risk factors to the SEC through their S-1 filings as part of the IPO process.
Additionally, companies must provide a complete list of risk factors in their Annual Reports (Form 10-K) or (Form 20-F) for “foreign private issuers”.
Quarterly Reports also include a section on risk factors (Form 10-Q) where companies are only required to update any changes since the previous report.
According to the SEC, risk factors should be reported concisely, logically and in “plain English” so investors can understand them.
How can I use TipRanks risk factors in my stock research?
Use the Risk Factors tab to get data about the risk factors of any company in which you are considering investing.
You can easily see the most significant risks a company is facing. Additionally, you can find out which risk factors a company has added, removed or adjusted since its previous disclosure. You can also see how a company’s risk factors compare to others in its sector.
Without reading company reports or participating in conference calls, you would most likely not have access to this sort of information, which is usually not included in press releases or other public announcements.
A simplified analysis of risk factors is unique to TipRanks.
What are all the risk factor categories?
TipRanks has identified 6 major categories of risk factors and a number of subcategories for each. You can see how these categories are broken down in the list below.
1. Financial & Corporate
- Accounting & Financial Operations - risks related to accounting loss, value of intangible assets, financial statements, value of intangible assets, financial reporting, estimates, guidance, company profitability, dividends, fluctuating results.
- Share Price & Shareholder Rights – risks related to things that impact share prices and the rights of shareholders, including analyst ratings, major shareholder activity, trade volatility, liquidity of shares, anti-takeover provisions, international listing, dual listing.
- Debt & Financing – risks related to debt, funding, financing and interest rates, financial investments.
- Corporate Activity and Growth – risks related to restructuring, M&As, joint ventures, execution of corporate strategy, strategic alliances.
2. Legal & Regulatory
- Litigation and Legal Liabilities – risks related to litigation/ lawsuits against the company.
- Regulation – risks related to compliance, GDPR, and new legislation.
- Environmental / Social – risks related to environmental regulation and to data privacy.
- Taxation & Government Incentives – risks related to taxation and changes in government incentives.
3. Production
- Costs – risks related to costs of production including commodity prices, future contracts, inventory.
- Supply Chain – risks related to the company’s suppliers.
- Manufacturing – risks related to the company’s manufacturing process including product quality and product recalls.
- Human Capital – risks related to recruitment, training and retention of key employees, employee relationships & unions labor disputes, pension, and post retirement benefits, medical, health and welfare benefits, employee misconduct, employee litigation.
4. Technology & Innovation
- Innovation / R&D – risks related to innovation and new product development.
- Technology – risks related to the company’s reliance on technology.
- Cyber Security – risks related to securing the company’s digital assets and from cyber attacks.
- Trade Secrets & Patents – risks related to the company’s ability to protect its intellectual property and to infringement claims against the company as well as piracy and unlicensed copying.
5. Ability to Sell
- Demand – risks related to the demand of the company’s goods and services including seasonality, reliance on key customers.
- Competition – risks related to the company’s competition including substitutes.
- Sales & Marketing – risks related to sales, marketing, and distribution channels, pricing, and market penetration.
- Brand & Reputation – risks related to the company’s brand and reputation.
6. Macro & Political
- Economy & Political Environment – risks related to changes in economic and political conditions.
- Natural and Human Disruptions – risks related to catastrophes, floods, storms, terror, earthquakes, coronavirus pandemic/COVID-19.
- International Operations – risks related to the global nature of the company.
- Capital Markets – risks related to exchange rates and trade, cryptocurrency.